Georgia Tech Procurement Assistance Center

  • Home
  • About Us
  • Training
    • Class Registration
    • On-demand Training
    • GTPAC COVID-19 Resource Page
    • Cybersecurity
    • Veterans Verification Video
    • GTPAC Community
    • Other Training Audio & Video
  • Useful Links
  • Team Directory
    • Albany Counselor
    • Atlanta Counselors
    • Augusta Counselor
    • Carrollton Counselor
    • Columbus Counselor
    • Gainesville Counselor
    • Savannah Counselor
    • Warner Robins Counselor
  • Directions
    • Atlanta – Training Facility
    • Atlanta – Office
    • Albany
    • Augusta
    • Carrollton
    • Columbus
    • Gainesville
    • Savannah
    • Warner Robins
  • COVID-19
  • New Client Application
  • Contact Us

Construction claims in the COVID era: lessons learned and best practices

February 22, 2021 By Andrew Smith

As we move into the second year of a global pandemic, construction contractors are not only taking stock of project delays and disruption experienced to date, but also preparing for more of the same.  What better time than now for contractors to take affirmative steps to protect themselves from default actions and to preserve their right to a time extension and/or contract adjustment.

Delay and Disruption in a Pandemic

As construction contractors well know, delay to agreed-upon construction schedules can result from a host of circumstances. The COVID-19 pandemic presents numerous challenges that may result in such delays, including, for example, project site closures or restrictions; labor impacts due to employee illness, exposure, and/or quarantine; new health and safety protocols such as on-site screenings; supply chain issues; subcontractor impacts; and delays to Government activities such as permitting and issuing approvals.  Of course, the type of delay and the extent to which a contractor may be entitled to additional time or compensation depend on the circumstances.

A threshold question is whether a delay to the project schedule is excusable in the first instance—i.e., whether the contractor will or should be excused from being found in default by virtue of the delay.  The Excusable Delay clause at FAR 52.249-14 provides some guidance.  This clause excuses contractors from default for failure to perform—including failure to make progress in a manner that endangers performance—if the failure “arises from causes beyond the control and without the fault or negligence of the contractor.”  Of potential relevance to COVID-related delays, the clause identifies specific causes deemed beyond contractors’ control.  These include epidemics, acts of God or the public enemy, and quarantine restrictions, among others.

A second question is whether a contractor delayed by such causes is due any relief.  To establish entitlement to an extension of time, the contractor must show that the cause of the delay was unforeseeable, beyond the contractor’s control and without the fault or negligence of the contractor, and that any Government caused delays were not concurrent with delays caused by the contractor.  To establish entitlement not only to time, but also to additional compensation, the contractor must show that the Government was the “sole proximate cause” of the delay such that “the contractor would not have been delayed for any other reason during that period.”

Continue reading at:  Wiley

Filed Under: Contracting Tips Tagged With: construction, delays

Recent Posts

  • DLA hosting event March 10th with special emphasis on Women-Owned Small Businesses
  • Navy Office of Small Business Programs holding three events in March
  • SBA hosting conversations with contracting officers forum Feb. 25th
  • Final rule, formal training on CMMC could hit this summer
  • Non-compete clauses in government contracting: a case study in enforceability

Popular Topics

8(a) abuse Army bid protest budget budget cuts certification construction contract awards contracting opportunities cybersecurity DoD DOJ False Claims Act FAR federal contracting federal contracts fraud GAO Georgia Tech government contracting government contract training government trends GSA GSA Schedule GTPAC HUBZone innovation IT Justice Dept. marketing NDAA OMB SBA SDVOSB set-aside small business small business goals spending subcontracting technology VA veteran owned business VOSB wosb

Contracting News

Final rule, formal training on CMMC could hit this summer

COFC: “Rule of two” must be analyzed before “any” acquisition

DOD’s cybersecurity certification requirements to appear in DHS contracts

Congressional Research Service publishes updated report on SBA’s 8(a) program

Congressional Research Service publishes new report on SBA’s HUBZone program

Read More

Contracting Tips

Non-compete clauses in government contracting: a case study in enforceability

NDAA for fiscal year 2021 includes numerous provisions impacting government contractors

Beware of the automated email response

Complying with the government’s restrictions on foreign telecommunications equipment

Construction claims in the COVID era: lessons learned and best practices

Read More

GTPAC News

DLA hosting event March 10th with special emphasis on Women-Owned Small Businesses

Navy Office of Small Business Programs holding three events in March

SBA hosting conversations with contracting officers forum Feb. 25th

USACE seeks vaccination center construction support

GTPAC updates cybersecurity resource page to include CMMC guidance

Read More

Georgia Tech News

Collective worm and robot “blobs” protect individuals, swarm together

The Partnership for Inclusive Innovation is now accepting applications for pilot programs

Georgia Tech will help manage DOE’s Savannah River National Laboratory

Dr. Abdallah testifies on U.S. competitiveness, research, STEM pipeline at Congressional hearing

Georgia Tech’s Technology Square Phase III to include George Tower

Read More

  • SAM.gov registration is free, and help with SAM is free, too
APTAC RSS Twitter GTPAC - 30th Year of Service

Copyright © 2021 · Georgia Tech - Enterprise Innovation Institute