Georgia Tech Procurement Assistance Center

  • Home
  • About Us
  • Training
    • Class Registration
    • On-demand Training
    • GTPAC COVID-19 Resource Page
    • Cybersecurity Video
    • Veterans Verification Video
    • GTPAC Community
    • Other Training Audio & Video
  • Useful Links
  • Team Directory
    • Albany Counselor
    • Athens Counselor
    • Atlanta Counselors
    • Augusta Counselor
    • Carrollton Counselor
    • Columbus Counselor
    • Gainesville Counselor
    • Savannah Counselor
    • Warner Robins Counselor
  • Directions
    • Athens
    • Atlanta – Training Facility
    • Atlanta – Office
    • Albany
    • Augusta
    • Carrollton
    • Columbus
    • Gainesville
    • Savannah
    • Warner Robins
  • COVID-19
  • New Client Application
  • Contact Us

Differing site conditions claims: Focus on actual costs incurred

March 15, 2016 By Andrew Smith

Today, we have a question for our federal construction readers:

If your project is operating within an anticipated budget, are you still entitled to the additional costs associated with a differing site condition? 

Recently, the Civilian Board of Contract Appeals (CBCA) answered our question with a resounding yes.

hardhatThis point is particularly important in the context of requests for equitable adjustments or claims asserted against the government.  You may think (or the government may try to convince you) that there is no entitlement when the project is below budget.  That is simply not the case.  The CBCA decision makes the point that damages are based upon the actual cost of performance — your bid should not be used against you.  In short, extra costs due to differing site conditions should always be tracked and documented — even if you are meeting or below a projected budget.

The case in question involved construction contractor Tucci and Sons Inc., which filed a claim seeking more than $80,000 on a DOT Federal Highway Administration (FHWA) contract for the reconstruction of a 9.7 mile stretch of highway in Mount Rainier National Park.  Tucci claimed that it experienced extra costs based on the unexpected need to work around a number of larger boulders impeding the work.

Keep reading this article at: http://www.mondaq.com/article.asp?articleid=470494

Filed Under: Contracting Tips Tagged With: actual cost, CBCA, Civilian Board of Contract Appeals, claim, construction, cost, damages, delays, FHWA, site conditions

Recent Posts

  • DoD publishes long awaited interim rule on CMMC
  • GSA Region 4 OSDBU hosting small business webinar
  • GTPAC launches COVID-19 resource page
  • GDEcD seeks GA Manufacturers and Distributors that can help with critical health care supply needs related to COVID-19
  • Georgia DOAS to hold 4th Annual Georgia Procurement Conference April 21-23, 2020

Popular Topics

8(a) abuse Army bid protest budget budget cuts certification construction contract awards contracting opportunities cybersecurity DoD DOJ False Claims Act FAR federal contracting federal contracts fraud GAO Georgia Tech government contracting government contract training government trends GSA GSA Schedule GTPAC HUBZone innovation IT Justice Dept. marketing NDAA OMB SBA SDVOSB set-aside small business small business goals spending subcontracting technology VA veteran owned business VOSB wosb

Contracting News

DoD publishes long awaited interim rule on CMMC

Small business subcontracting for cloud computing gets easier

Long awaited changes to WOSB/EDWOSB regulations expected this summer

The CMMC has arrived: DoD publishes version 1.0 of its new cybersecurity framework

GSA keeping ‘on track’ with schedule consolidation

Read More

Contracting Tips

A guide to labor and employment obligations for federal contractors

Who pays for CMMC certification?

Other transaction agreements: Where does an unsuccessful bidder go?

Knowledge is power, if you know how to use it

EAJA provides relief to construction contractor for government’s bad actions

Read More

GTPAC News

GSA Region 4 OSDBU hosting small business webinar

GTPAC launches COVID-19 resource page

GDEcD seeks GA Manufacturers and Distributors that can help with critical health care supply needs related to COVID-19

Georgia DOAS to hold 4th Annual Georgia Procurement Conference April 21-23, 2020

MICC Fort Stewart hosting acquisition forecast open house on Thursday, Feb. 6, 2020

Read More

Georgia Tech News

Dr. Abdallah testifies on U.S. competitiveness, research, STEM pipeline at Congressional hearing

Georgia Tech’s Technology Square Phase III to include George Tower

Student surprises his teacher with Georgia Tech acceptance news

Georgia Tech Applied Research will support DHS information safeguarding effort

$25 million project will advance DNA-based archival data storage

Read More

  • SAM.gov registration is free, and help with SAM is free, too
APTAC RSS Twitter GTPAC - 30th Year of Service

Copyright © 2021 · Georgia Tech - Enterprise Innovation Institute